Web Site Development Agreement

This Agreement is made as of the date of registration, between (“CLIENT”) a Limited Partnership having its principal place of business at, and BEAM LOCAL. (“BEAM LOCAL”), a corporation having its principal place of business at Toronto Ontario, Canada.

WHEREAS CLIENT desires to establish a web site to promote and sell its [products and/or services] to the public on the Internet;

AND WHEREAS BEAM LOCAL is in the business of and has substantial expertise in providing design and development services in connection with creating sites on the Internet;

AND WHEREAS BEAM LOCAL desires to design, develop and assist in the implementation of a web site for Client under the terms and conditions set forth in this Agreement;NOW THEREFORE, in consideration of the respective covenants set forth herein, the parties agree as provided herein.
Definitions

Terms used in this Agreement and not otherwise defined shall have the following meanings:

“Agreement” means this agreement and the annexed schedules which are deemed incorporated herein, together with any future written and executed amendments.

“Client Content” means all of the materials supplied by Client to BEAM LOCAL for display or use in connection with Web Site, including text, audio and/or visual works, photos, and brand materials such as trade names, service marks, or logos owned or licensed by Client, including all copyrights, and trademark, patent, and trade secret rights vested therein.

“Website” means the website designed and maintained by BEAM LOCAL for Client.

“Developer Materials” means any computer software, tools, HTML script, know-how, techniques, concepts, or ideas related to the design, development, or implementation of the Web Site and any text, visual displays, audio recordings, video, or other works of authorship related to the display of the Web Site that are owned by BEAM LOCAL as of the date of this Agreement or that are licensed by BEAM LOCAL from a third party.

“Documentation” means the user documents that fully explain to Client the design and the operation of the Web Site.

“Host Server” means the hosting computer environment that has been designated by Client to host the Web Site.

“Web Site” means the branded site on the Internet that will be designed, developed, and implemented for Client by BEAM LOCAL under this Agreement.

Nature of Services

Website. Subject to the terms and conditions of this Agreement, BEAM LOCAL shall install the website to the Client within twenty (20) business days of the Client providing BEAM LOCAL of written confirmation of their choice of website design. Client shall have ultimate artistic and editorial control of the Web Site, including its branding, displays, integration, and look and feel.

Web Site Installation. BEAM LOCAL shall install or assist Client in installing the Web Site on a computer server operated by Beam Local and approved in advance by the Client.

Payments

Initial Payment. Upon the execution of this Agreement, Client shall pay to BEAM LOCAL the sum of the initial set up fee agreed upon. Subject to the “Satisfaction guarantee” below, the initial setup fee is non-refundable anytime past 60 days of signup.

Web Site Services. In consideration for the services rendered by BEAM LOCAL under this Agreement, including but not limited to support and maintenance of the website, Client shall pay to BEAM LOCAL the fixed price agreed upon per month, plus applicable taxes, payable every 30 days from the initial registration throughout the term of this Agreement.

Expenses. Expenses incurred by BEAM LOCAL in the course of delivering the Services hereunder shall be for the account of BEAM LOCAL.

Payment Methods. Beam Local only accepts payment by Visa or Mastercard.

Late Payments. Interest may be charged by BEAM LOCAL on amounts payable to it which are not paid within 30 days from the date such amount becomes payable to BEAM LOCAL hereunder at the rate of ten percent (10%) per annum, calculated monthly commencing with the date payment was due.

Re-Design or rebuild. Should the client wish to change or alter the design, general layout, colour, or general theme of the website BEAM LOCAL will provide a quote based on the scale and scope of work involved.

Term and Termination

Term and Termination

Term Commencement. This Agreement shall become effective when the client registers to have a site built.

Term for Contracted Clients. If a term contract was signed other than a monthly subscription service, this Agreement shall remain in effect for the minimum length of the contract after BEAM LOCAL receives initial registration. The terms agreed upon in the contract, including pricing, shall remain fixed and unchangeable for the duration of the contract term.

Renewal and Termination for Contracted Clients. Following the term, the agreement shall renew on an annual or monthly basis and remain in effect until BEAM LOCAL receives written notice of termination from the Client twenty (20) days prior to the next renewal, or there is a termination for default or termination for non-payment.

Cancellation and Termination for Non-Contracted Clients. If a client does not have a minimum term commitment, BEAM LOCAL reserves the right to modify the terms of this Agreement or terminate services at any time, with or without cause. Such changes or termination will become effective immediately upon notification to the CLIENT.

Notification of Changes or Termination. For non-contracted clients, any changes to the terms, including pricing or service termination, will be communicated to the CLIENT by any reasonable means including but not limited to email, postal mail, or publication on BEAM LOCAL’s website.
Payments

Initial Payment. Upon the execution of this Agreement, Client shall pay to BEAM LOCAL the sum of the initial set up fee agreed upon.

Pricing for Contracted Clients. For clients with a term contract, the pricing agreed upon shall remain fixed for the duration of the contract term.

Pricing Adjustments for Non-Contracted Clients. For clients without a minimum term commitment, BEAM LOCAL reserves the right to adjust the pricing of services at any time. Any such price adjustments will be communicated to the CLIENT by any reasonable means including but not limited to email, postal mail, or publication on BEAM LOCAL’s website.

Term Commencement. This Agreement shall become effective when a client registers to have a site built.

Term. If a term contract was signed, this Agreement shall remain in effect for at minimum the length of the contract after BEAM LOCAL receives initial registration. Following the term the agreement shall renew on annual or monthly basis and remain in effect until Beam Local receives written notice of termination from the Client twenty (20) days prior to the next renewal, or there is a termination for default or termination for non-payment. Following termination, (a) client will be responsible to pay the remaining term b) after which no amount not then payable under this Agreement will become payable nor will any amount paid be reimbursable, and (b) BEAM LOCAL shall own all work product produced up to such time and BEAM LOCAL.

Cancellation. If a client does not have a minimum term commitment, clients may cancel their service at anytime. Cancellation must be provided in writing to Beam Local, and sent from the customer admin on the account. If the cancellation date occurs in the middle of a payment period, no proration or credit thereof will be applied the account.

Termination of Services. BEAM LOCAL reserves the unconditional and unilateral right to discontinue services provided under this Agreement to the CLIENT at any time, with or without cause. In the event that BEAM LOCAL elects to discontinue services, BEAM LOCAL will provide the CLIENT with a notice of termination, which may be delivered by any reasonable means including but not limited to email, postal mail, or publication on BEAM LOCAL’s website. Such termination shall become effective immediately upon delivery of the notice to the CLIENT. Upon termination, BEAM LOCAL shall have no further obligations to the CLIENT under this Agreement, except as may be otherwise provided herein or required by applicable law.

Satisfaction guarantee. Beam Local agrees to provide a money back guarantee within 60 days of signup if the customer is not satisfied with the service provided.

Transfer of website. Upon a terminating event within the first 12 months of service, BEAM LOCAL can supply all of your website files for use in a migration by a third party for a fee of $495. Upon a terminating event following the first 12 months of paid service, BEAM LOCAL can supply all of your website files for use in a migration by a third party for a fee of $295.

Termination for Default. Either party may provide written notice to the other of any default to any term or obligation contained in this Agreement. The defaulting party will have ten (10) days to cure that default, failing which the non-defaulting party may terminate this Agreement.

Domain Names. Upon the terminating event, BEAM LOCAL agrees to transfer, assign or make available to the Client the domain name of every website which is the subject of this agreement for a fee of $99.

Termination for Non-Payment. If any part of Client’s account remains outstanding for a period of thirty (30) days or more from the date the initial payment was due, BEAM LOCAL, may remove the website from the host server and terminate this Agreement immediately. Should Client wish to reinstate this Agreement, BEAM LOCAL will be entitled to a fee of two hundred dollars ($200.00) associated with the reactivation of the website, in addition to amounts already owing.

Client Responsibilities

Duty to Cooperate. The parties hereby acknowledge and agree that the successful completion of the services hereunder shall require the full and mutual good faith and cooperation of the parties. In the event Client has delayed in providing, or failed to provide, BEAM LOCAL with information that is required to proceed with the development or installation of the Web Site, then BEAM LOCAL’s obligations, which are dependent upon such information or approval, shall be extended to reflect such delay.

Client Content. Client shall be solely responsible for the accuracy and content of Client Content, including any claims or liability that may arise therefrom.

Confidentiality

Confidential Information. Confidential Information shall mean all unpublished technical information (such as computer programs, tools, or technical processes), all artistic information (such as product design) and all unpublished business and financial information (such as product promotion or business plans, advertising revenues and relationships, marketing data and projections) disclosed by either party to the other in the course of designing, developing, or implementing the Web Site which information is in writing, except such information which (i) was previously known to the information recipient as of the time of its disclosure, (ii) thereafter becomes part of the public domain through a source other than the receiving party or (iii) is subsequently disclosed by a third party not under a confidentiality agreement with the providing party.

Standard of Care. The parties shall not disclose Confidential Information to anyone other than their employees who have a need to know in connection with the performance of Services under this Agreement, and as has been authorized in writing in advance by the providing party.

Return of Confidential Information. Upon completion of the services hereunder, the parties shall deliver to each other all materials containing the Confidential Information of the other, or make such other reasonable disposition as the providing party may direct. However, the confidentiality obligations of each party shall survive the expiration or termination of this Agreement.

Third Party Licenses.

To the extent any website is delivered with code, content, or photography, proprietary to, or owned by a third party, Beam Local will, prior to delivery to the Client, ensure that any code, content or photography has sufficient licenses for use by Client or Beam Local will obtain a license from the owner granting Client royalty-free right to use such material at no additional cost to the Client.

Proprietary Rights.

Client Content. All right, title, and interest to Client Content shall remain the sole and exclusive property of the Client. All Client Content shall be promptly returned to Client upon request. Nothing in this Agreement shall be construed to grant to BEAM LOCAL any ownership or licensing rights to the Client Content. Client hereby grants to BEAM LOCAL a non-transferable limited license during the term of this Agreement to use Client Content, including the making of copies, solely for the benefit of the Client in accordance with the terms and conditions of this Agreement.

Developer Materials. BEAM LOCAL shall at all times be and remain the sole and exclusive owner of all Developer Materials. To the extent the Web Site utilizes Developer Materials, whether specially adopted for use by Client or not, BEAM LOCAL grants to Client a non-exclusive license to use the same for the sole and exclusive purpose of enabling Client to transmit, use and display the Web Site. Client hereby acknowledges that BEAM LOCAL is in the business of designing and developing web sites and accordingly BEAM LOCAL will be providing to third parties services similar to the services provided to Client and will be using Developer Materials in providing such services. Therefore, nothing in this Agreement shall be construed so as to preclude BEAM LOCAL from developing, using, or marketing Developer Materials to other prospects and clients.

BEAM LOCAL Representations, Warranties and Covenants

Performance of Services. BEAM LOCAL services hereunder will be rendered using sound professional practices by knowledgeable, trained, and qualified personnel in appropriate numbers to perform this Agreement in a timely fashion.

BEAM LOCAL agrees to provide services, including any limited or unlimited service level (UNLIMITED SUPPORT) agreements on a best effort, commercially reasonable, good faith basis.

BEAM LOCAL reserves the right to limit services at their sole discretion for reasons including but not limited to; abuse of good faith, an unreasonable request, or a level of requests which far exceed network averages.

BEAM LOCAL requires that all service level agreement requests be made by the CLIENT, and not through an intermediary or third party service provider. BEAM LOCAL is not an intermediary service provider.

Developer Materials. BEAM LOCAL hereby represents and warrants that to its best knowledge the Developer Materials do not infringe a copyright, trademark or patent, nor any trade secret arising under applicable law.

Authority. BEAM LOCAL hereby represents and warrants that it has the power and authority to enter into this Agreement and that to its best knowledge there is no outstanding contract or commitment or legal impediment of any kind that conflicts with this Agreement or that may limit or impair the rights granted hereunder.

Viruses. BEAM LOCAL hereby represents and warrants that the Web Site will not contain any viruses, defects, clocks, timers, counters, or other limiting or disabling codes, designs or routines or any obscene, threatening or malicious content.

Client Warranties

Client Content. Client hereby represents and warrants that to its best knowledge the Client Content does not infringe a copyright, trademark or patent, nor any trade secret arising under applicable law.

Authority. Client hereby represents and warrants that it has the power and authority to enter into this Agreement and that to its best knowledge there is no outstanding contract or commitment or legal impediment of any kind that conflicts with this Agreement or that may limit or impair the rights granted hereunder.

Indemnification Against Third Party Claims

Mutual Indemnifications. Each party shall indemnify, defend, and hold harmless the other and its directors, officers, employees, and agents with respect to any claim, demand, cause of action, debt or liability (the “Claims”) and pay any costs or damages including reasonable attorneys fees that may be finally awarded against the Claimant to the extent the Claims if true, would constitute a breach of the warranties and representations made hereunder by the warrantor regarding the Developer Materials and the Client Content to the other party, or arise out of the gross negligence or wilful misconduct of the indemnifying party.

Notice. In claiming any indemnification hereunder, the claimant shall promptly provide the indemnifying party with a written notice describing the claim that the indemnified party believes falls within the scope of the indemnifications made hereunder.

Control. The indemnifying party shall at its own expense defend any such claim and shall control such defense and all negotiations to settle any such claim provided that a binding settlement shall not be made without the indemnified party’s written consent, which shall not be unreasonably withheld.

Limitation of Liability

Indirect or Consequential Damages. NEITHER PARTY WILL BE LIABLE TO THE OTHER FOR INDIRECT, INCIDENTAL, CONSEQUENTIAL, SPECIAL, OR EXEMPLARY DAMAGES ARISING OUT OF THIS AGREEMENT, EVEN IF SUCH PARTY HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES.

Time Limitation. No action, regardless of the form, arising out of the undertakings under this Agreement, may be brought by either party more than two years after the cause of action has occurred.

General Provisions

Amendments. BEAM LOCAL reserves the right to unilaterally amend, change, or modify the terms of this Agreement, including but not limited to the pricing of services provided under this Agreement, at its discretion. Any such amendments, changes, or modifications shall be effective immediately upon notification to the CLIENT, which may be provided by any reasonable means including but not limited to email, posting on BEAM LOCAL’s website, or through direct communication. The CLIENT’s continued use of BEAM LOCAL’s services after such notification will constitute the CLIENT’s acceptance of the amended terms.

Assignment. This Agreement may not be assigned by either party other than with the consent of the other party, provided that this Agreement may be assigned or otherwise transferred by Client to any person or entity related to Client or its shareholders. Upon such consent the terms and conditions of this Agreement shall extend to and bind any permitted successor or assign.

Entire Agreement. This Agreement constitutes the entire agreement between the parties with respect to the subject matter hereof, and supersedes all oral or written communications between the parties.

Force Majeure. If the performance of this Agreement by either party is prevented or delayed or otherwise made impracticable by reason of any cause beyond the control of either party, that party shall be excused therefrom.

Governing Law. This Agreement shall be governed by the laws of the Province of Ontario, Canada without regard to its conflict of laws rules and BEAM LOCAL and Client agree that the sole venue and jurisdiction for disputes arising from this Agreement shall be the courts of the Province of Ontario, and the parties hereby submit to the jurisdiction of such courts.

Notices. All notices made under this Agreement shall be by way of email: if to BEAM LOCAL, to support@beamlocal.com, and if to client by way of email. Notice is effective the day it is sent.

Relationship of Parties. In the performance of this Agreement, BEAM LOCAL and its project staff are acting solely as independent contractors of Client. This Agreement shall not be interpreted to create a partnership or joint venture; neither party is the other’s partner, employee, or agent.

Currency. All references to dollars in this Agreement refer to the lawful currency of Canada.

Vendor Marketing. BEAM LOCAL may identify Client as a BEAM LOCAL client in advertising, publicity, or similar materials distributed or displayed to prospective clients, and BEAM LOCAL may display pre-approved portions of the Web Site for the purpose of marketing and advertising its services to others.

IN WITNESS WHEREOF, the parties have executed this Agreement as of the date stated above.

The parties hereby irrevocably attorn to the exclusive jurisdiction of the courts of Ontario with respect to any matter arising under or related to this Agreement. The parties hereby irrevocably consent to any litigation arising out of this agreement being in the court in Toronto, Ontario

During the customized initial build customers will receive up to 3 rounds of revisions prior to launch.